联合合同法庭和伊拉克标准招标文件延期规定的比较

IF 1.7 Q3 MATERIALS SCIENCE, MULTIDISCIPLINARY
Wurood R. Zain-alabdeen, Sawsan M. Rasheed
{"title":"联合合同法庭和伊拉克标准招标文件延期规定的比较","authors":"Wurood R. Zain-alabdeen, Sawsan M. Rasheed","doi":"10.1515/jmbm-2022-0063","DOIUrl":null,"url":null,"abstract":"Abstract Many contractors face challenges in completing the project on time due to delays arising for various reasons, including reasons beyond the contractor’s control, such as force majeure, exceptionally bad weather conditions, changes, etc. As a result, contractors submit a time extension claim to make up for lost time and set a later completion date to complete the project. Each contract has its terms for the extension of time (EOT). Therefore, the objective of this article is to study the provisions for extending the time when the reasons are beyond the control of the contractor according to Iraqi Standard Bidding Documents for Procurement of Works (SBDW) and the Joint Contracts Tribunal (SBC/Q 2016). The article also aims to show the extent of the difference between the two contracts in applying these provisions. The study found that when submitting a claim in the Iraqi SBDW, the contractor shall consider the notifications relating to it as per the specified period. Therefore, they will not be considered if claims are submitted after that period. In SBC/Q 2016, submitting a claim notice is not required to gain additional time. Therefore, the failure to provide notice does not forfeit the right to claim additional time. This study enhances the contractor’s knowledge of the terms related to the EOT under the two contracts, reducing the disputes resulting from a misunderstanding of these provisions.","PeriodicalId":17354,"journal":{"name":"Journal of the Mechanical Behavior of Materials","volume":"31 1","pages":"580 - 586"},"PeriodicalIF":1.7000,"publicationDate":"2022-01-01","publicationTypes":"Journal Article","fieldsOfStudy":null,"isOpenAccess":false,"openAccessPdf":"","citationCount":"1","resultStr":"{\"title\":\"Comparison of time extension provisions between the Joint Contracts Tribunal and Iraqi Standard Bidding Document\",\"authors\":\"Wurood R. Zain-alabdeen, Sawsan M. Rasheed\",\"doi\":\"10.1515/jmbm-2022-0063\",\"DOIUrl\":null,\"url\":null,\"abstract\":\"Abstract Many contractors face challenges in completing the project on time due to delays arising for various reasons, including reasons beyond the contractor’s control, such as force majeure, exceptionally bad weather conditions, changes, etc. As a result, contractors submit a time extension claim to make up for lost time and set a later completion date to complete the project. Each contract has its terms for the extension of time (EOT). Therefore, the objective of this article is to study the provisions for extending the time when the reasons are beyond the control of the contractor according to Iraqi Standard Bidding Documents for Procurement of Works (SBDW) and the Joint Contracts Tribunal (SBC/Q 2016). The article also aims to show the extent of the difference between the two contracts in applying these provisions. The study found that when submitting a claim in the Iraqi SBDW, the contractor shall consider the notifications relating to it as per the specified period. Therefore, they will not be considered if claims are submitted after that period. In SBC/Q 2016, submitting a claim notice is not required to gain additional time. Therefore, the failure to provide notice does not forfeit the right to claim additional time. This study enhances the contractor’s knowledge of the terms related to the EOT under the two contracts, reducing the disputes resulting from a misunderstanding of these provisions.\",\"PeriodicalId\":17354,\"journal\":{\"name\":\"Journal of the Mechanical Behavior of Materials\",\"volume\":\"31 1\",\"pages\":\"580 - 586\"},\"PeriodicalIF\":1.7000,\"publicationDate\":\"2022-01-01\",\"publicationTypes\":\"Journal Article\",\"fieldsOfStudy\":null,\"isOpenAccess\":false,\"openAccessPdf\":\"\",\"citationCount\":\"1\",\"resultStr\":null,\"platform\":\"Semanticscholar\",\"paperid\":null,\"PeriodicalName\":\"Journal of the Mechanical Behavior of Materials\",\"FirstCategoryId\":\"1085\",\"ListUrlMain\":\"https://doi.org/10.1515/jmbm-2022-0063\",\"RegionNum\":0,\"RegionCategory\":null,\"ArticlePicture\":[],\"TitleCN\":null,\"AbstractTextCN\":null,\"PMCID\":null,\"EPubDate\":\"\",\"PubModel\":\"\",\"JCR\":\"Q3\",\"JCRName\":\"MATERIALS SCIENCE, MULTIDISCIPLINARY\",\"Score\":null,\"Total\":0}","platform":"Semanticscholar","paperid":null,"PeriodicalName":"Journal of the Mechanical Behavior of Materials","FirstCategoryId":"1085","ListUrlMain":"https://doi.org/10.1515/jmbm-2022-0063","RegionNum":0,"RegionCategory":null,"ArticlePicture":[],"TitleCN":null,"AbstractTextCN":null,"PMCID":null,"EPubDate":"","PubModel":"","JCR":"Q3","JCRName":"MATERIALS SCIENCE, MULTIDISCIPLINARY","Score":null,"Total":0}
引用次数: 1

摘要

摘要由于各种原因造成的延误,包括不可抗力、异常恶劣的天气条件、变化等承包商无法控制的原因,许多承包商在按时完成项目方面面临挑战。因此,承包商提出延期索赔,以弥补损失的时间,并设定更晚的完工日期来完成项目。每份合同都有其延期条款。因此,本条的目的是研究根据伊拉克工程采购标准招标文件(SBDW)和联合合同法庭(SBC/Q 2016),当原因超出承包商控制范围时延长时间的规定。该条还旨在说明两份合同在适用这些条款方面的差异程度。研究发现,在伊拉克SBDW提交索赔时,承包商应按照规定的期限考虑与之相关的通知。因此,如果在此期间之后提出索赔,则不考虑这些索赔。在SBC/Q 2016中,提交索赔通知无需获得额外时间。因此,未提供通知并不丧失要求额外时间的权利。这项研究提高了承包商对两份合同下EOT相关条款的了解,减少了因误解这些条款而产生的争议。
本文章由计算机程序翻译,如有差异,请以英文原文为准。
Comparison of time extension provisions between the Joint Contracts Tribunal and Iraqi Standard Bidding Document
Abstract Many contractors face challenges in completing the project on time due to delays arising for various reasons, including reasons beyond the contractor’s control, such as force majeure, exceptionally bad weather conditions, changes, etc. As a result, contractors submit a time extension claim to make up for lost time and set a later completion date to complete the project. Each contract has its terms for the extension of time (EOT). Therefore, the objective of this article is to study the provisions for extending the time when the reasons are beyond the control of the contractor according to Iraqi Standard Bidding Documents for Procurement of Works (SBDW) and the Joint Contracts Tribunal (SBC/Q 2016). The article also aims to show the extent of the difference between the two contracts in applying these provisions. The study found that when submitting a claim in the Iraqi SBDW, the contractor shall consider the notifications relating to it as per the specified period. Therefore, they will not be considered if claims are submitted after that period. In SBC/Q 2016, submitting a claim notice is not required to gain additional time. Therefore, the failure to provide notice does not forfeit the right to claim additional time. This study enhances the contractor’s knowledge of the terms related to the EOT under the two contracts, reducing the disputes resulting from a misunderstanding of these provisions.
求助全文
通过发布文献求助,成功后即可免费获取论文全文。 去求助
来源期刊
Journal of the Mechanical Behavior of Materials
Journal of the Mechanical Behavior of Materials Materials Science-Materials Science (miscellaneous)
CiteScore
3.00
自引率
11.10%
发文量
76
审稿时长
30 weeks
期刊介绍: The journal focuses on the micromechanics and nanomechanics of materials, the relationship between structure and mechanical properties, material instabilities and fracture, as well as size effects and length/time scale transitions. Articles on cutting edge theory, simulations and experiments – used as tools for revealing novel material properties and designing new devices for structural, thermo-chemo-mechanical, and opto-electro-mechanical applications – are encouraged. Synthesis/processing and related traditional mechanics/materials science themes are not within the scope of JMBM. The Editorial Board also organizes topical issues on emerging areas by invitation. Topics Metals and Alloys Ceramics and Glasses Soils and Geomaterials Concrete and Cementitious Materials Polymers and Composites Wood and Paper Elastomers and Biomaterials Liquid Crystals and Suspensions Electromagnetic and Optoelectronic Materials High-energy Density Storage Materials Monument Restoration and Cultural Heritage Preservation Materials Nanomaterials Complex and Emerging Materials.
×
引用
GB/T 7714-2015
复制
MLA
复制
APA
复制
导出至
BibTeX EndNote RefMan NoteFirst NoteExpress
×
提示
您的信息不完整,为了账户安全,请先补充。
现在去补充
×
提示
您因"违规操作"
具体请查看互助需知
我知道了
×
提示
确定
请完成安全验证×
copy
已复制链接
快去分享给好友吧!
我知道了
右上角分享
点击右上角分享
0
联系我们:info@booksci.cn Book学术提供免费学术资源搜索服务,方便国内外学者检索中英文文献。致力于提供最便捷和优质的服务体验。 Copyright © 2023 布克学术 All rights reserved.
京ICP备2023020795号-1
ghs 京公网安备 11010802042870号
Book学术文献互助
Book学术文献互助群
群 号:481959085
Book学术官方微信